Unimark EC3000 Series Spezifikationen PDF herunterladen (Seite 263)

Exhibit N

00720. FORM OF PAYMENT BOND

BY THIS BOND, We _______________________________________, as Principal,

hereinafter called Contractor, and _______________________________, as Surety, are bound

to the Board of County Commissioners of Broward County, Florida, as Obligee, hereinafter

called County, in the amount of ______________________________ Dollars ($____________)

for the payment whereof Contractor and Surety bind themselves, their heirs, executors,

administrators, successors and assigns, jointly and severally.

WHEREAS, Contractor has by written agreement entered into a Contract, Bid/Contract

No.: _____________, awarded the _______ day of __________________, 20____, with

County which Contract Documents are by reference incorporated herein and made a part

hereof, and specifically include provision for liquidated damages, and other damages identified,

and for the purposes of this Bond are hereafter referred to as the "Contract";

THE CONDITION OF THIS BOND is that if Contractor:

1) Pays County all losses, liquidated damages, expenses, costs and attorney’s fees

including appellate proceedings, that County sustains because of default by Contractor

under the Contract; and

2) Promptly makes payments to all claimants as defined by Florida Statute 255.05(1) for all

labor, materials and supplies used directly or indirectly by Contractor in the performance

of the Contract;

THEN CONTRACTOR'S OBLIGATION SHALL BE VOID; OTHERWISE, IT SHALL

REMAIN IN FULL FORCE AND EFFECT SUBJECT, HOWEVER, TO THE

FOLLOWING CONDITIONS:

a) A claimant, except a laborer, who is not in privity with Contractor and who has

not received payment for its labor, materials, or supplies shall, within forty-five

(45) calendar days after beginning to furnish labor, materials, or supplies for the

prosecution of the work, furnish to Contractor a notice that he intends to look to

the bond for protection.

b) A claimant who is not in privity with Contractor and who has not received

payment for its labor, materials, or supplies shall, within ninety (90) calendar

days after performance of the labor or after complete delivery of the materials or

supplies, deliver to Contractor and to the Surety, written notice of the

performance of the labor or delivery of the materials or supplies and of the

nonpayment.

Exhibit 3

Page 263 of 278

1 2 ... 258 259 260 261 262 263 264 265 266 267 268 ... 277 278

Keine Kommentare

Unimark EC3000 Series Spezifikationen Seite 263